FEES & DEPOSITS
A 50% deposit of the total fee is due immediately to begin the website design and development work. The remaining 50% shall become due when the work is completed to your reasonable satisfaction by the online launch date. Wein & Co. reserves the right not to commence any work until the deposit has been paid in full.
The deposit is not refundable if the development work has been started and you terminate the contract through no fault of Wein & Co.
SUPPLY OF MATERIALS
You must supply all materials and information required by Wein & Co. to complete the work in accordance with any agreed specification dates. Such materials may include, but are not limited to, photographs, written copy, logos and other printed material. Where there is any delay in supplying these materials to Wein & Co. which leads to a delay in the completion of work, Wein & Co. has the right to extend any previously agreed deadlines by a reasonable amount.
Where you fail to supply materials, and that prevents the progress of the work, Wein & Co. has the right to invoice you for any part or parts of the work already completed.
VARIATIONS
Wein & Co. is pleased to offer you the opportunity to make revisions to the design. However, Wein & Co. has the right to limit the number of design proposals to a reasonable amount and may charge for additional designs if you make a change to the original design specification.
Once the website theme has been signed off, and Wein & Co. commences the website development phase, only minimal changes can be accepted without additional charges.
Any major deviation from the specification will be charged at the rate of $85.00 per hour.
AGREED SCOPE, PERIOD, PRICE, PROJECT DELAYS & CLIENT LIABILITY
Any projects, services and rates supplied are limited to what is specifically set forth and based on a set number of hours. Any additional services will require an agreed quote on additional hours.
Changes and additions outside the scope of the project will be quoted and invoiced. You will be advised on all costs, changes and additions before commencement of the additional work. Expenses are itemized on each invoice.
Any time frames or estimates that Wein & Co. gives are contingent upon your full co-operation and complete and final content in photography for the work pages. During development there is a certain amount of feedback required in order to progress to subsequent phases. It is required that a single point of contact be appointed from your side and be made available on a daily basis in order to expedite the feedback process.
APPROVAL OF WORK
On completion of the work you will be notified and have the opportunity to review it. You must notify Wein & Co. in writing of any unsatisfactory points within 7 days of such notification. Any of the work which has not been reported in writing to Wein & Co. as unsatisfactory within the 7-day review period will be deemed to have been approved. Once approved, or deemed approved, work cannot subsequently be rejected. The project will be deemed to have been completed and the 50% balance of the project price will become due.
The only exception to the above is if the delays are a result of injury or illness.
REJECTED WORK
If you reject any of Wein & Co.’s work within the 7-day review period, or not approve subsequent work performed by Wein & Co. to remedy any points recorded as being unsatisfactory, and Wein & Co., acting reasonably, consider that you have been unreasonable in any rejection of the work, Wein & Co. can elect to treat this project as at an end and take measures to recover payment for the completed work.
ACCEPTANCE OF WEBSITE
Once the project has been completed, as determined by Wein & Co. Creative, we will notify you either in writing, and provide you with an opportunity to access the website. If you determine that the website does not comply with the project components outlined in the initial meeting, Wein & Co. Creative agrees to;
a) Perform the corrections of errors free of charge to the system Wein & Co. Creative has developed.Wein & Co. Creative is not responsible for errors on third party software.
b) Wein & Co. Creative will carry out simple aesthetic changes, modifications to meet the client’s demands. These changes do not include development of new function into the website.
Any significant changes will require additional funding to complete the requirements.
PAYMENT
Upon completion of the 7-day review period, Wein & Co. will invoice you for the 50% balance of the project. If there are any outstanding payments, Wein & Co. Creative reserves the right to refrain from proceeding with more work for the client.
WARRANTY BY YOU AS TO OWNERSHIP OF INTELLECTUAL PROPERTY RIGHTS
You must obtain all necessary permissions and authorities in respect of the use of all copy, graphic images, registered company logos, names and trade marks, or any other material that you supply to Wein & Co. to include in your website or web applications.
You must indemnify Wein & Co. and hold Wein & Co. harmless from any claims or legal actions related to the content of your website.
SEARCH ENGINES
Wein & Co. does not guarantee any specific position in search engine results for your website. Wein & Co. performs basic search engine optimization according to current best practice.
CONSEQUENTIAL LOSS
Wein & Co. shall not be liable for any loss or damage which you may suffer which is in any way attributable to any delay in performance or completion of the project, however that delay arises.
DISCLAIMER
To the full extent permitted by law, all terms, conditions, warranties, undertakings, inducements or representations whether express, implied, statutory or otherwise (other than the express provisions of these terms and conditions) relating in any way to the services Wein & Co. provides to you are excluded. Without limiting the above, to the extent permitted by law, any liability of Wein & Co. Creative under any term, condition, warranty or representation that by law cannot be excluded is, where permitted by law, limited at our option to the replacement, re-repair or re-supply of the services or the payment of the cost of the services that Wein & Co. was hired to perform.
SUBCONTRACTING
Wein & Co. reserves the right to subcontract any services that Wein & Co. has agreed to perform for you as Wein & Co. sees fit. Wein & Co. will not share any confidential data or logins with subcontractors aside from the website login.
NON-DISCLOSURE
Wein & Co. (and any subcontractors engaged) agree that Wein & Co. will not at any time disclose any of your confidential information to any third party.
ADDITIONAL EXPENSES
You agree to reimburse Wein & Co. for any requested expenses that will be noted in the quote including but not limited to the purchase of templates, third party software, stock photographs, fonts, domain name registration, web hosting or comparable expenses.
BACKUPS
You are responsible for maintaining your own backups with respect to your website and Wein & Co. will not be liable for restoring any client data or client websites except to the extent that such data loss arises out of a negligent act or omission by Wein & Co.
OWNERSHIP OF DOMAIN NAMES & WEB HOSTING
Wein & Co. will recommended an Internet domain registrar and web hosting company where you can purchase a domain name, hosting, web security, and any other items your business may require. Once you create an account, Wein & Co. will require the login credentials in order to set up your website.
GOVERNING LAW
The agreement constituted by these terms and conditions and any proposal will be construed according to and is governed by the laws of Vancouver. You and Wein & Co. Creative submit to the non-exclusive jurisdiction of the courts in and of Vancouver in relation to any dispute arising under these terms and conditions or in relation to any services Wein & Co. performs for you.
CROSS BROWSER COMPATIBILITY
By using current versions of well supported content management systems such as “Wordpress”, Wein & Co. endeavours to ensure that the web sites Wein & Co. creates are compatible with all current modern web browsers such as the most recent versions of Internet Explorer, Firefox, Google Chrome and Safari. Third party extensions, where used, may not have the same level of support for all browsers. Where appropriate Wein & Co. will substitute alternative extensions or implement other solutions, on a best effort basis, where any incompatibilities are found.
E-COMMERCE
You are responsible for complying with all relevant laws relating to e-commerce, and to the full extent permitted by law will hold harmless, protect, and defend and indemnify Wein & Co. Creative and its subcontractors from any claim, penalty, tax, tariff loss or damage arising from your or your clients’ use of Internet electronic commerce.
AUTHORIZATION
You authorize Wein & Co. Creative to perform services which may include, but is not limited to, accessing your domain control panels, email hosting, DNS, hosting account and disk space, creating databases and applications, and submitting the project to search engines.
OWNERSHIP
You have ownership of the website supplied by Wein & Co. Creative once it is fully paid.Wein & Co. Creative will at all times be and remain the sole and exclusive owner of any custom web development or software created in any format used or made part of the website which is not provided by you or a third party (open source). 3rd Party software such as plugins remain the property of Wein & Co. Creative, and may not be transferred without approval from Wein & Co. Creative. Except as expressly authorized by Wein & Co. Creative, you will not copy, modify, distribute or transfer (by any means), display, sublicense, rent, reverse engineer, decompile or disassemble Wein & Co. Creative’s properties.
LICENSING
Once you have paid Wein & Co. in full for our work we grant to you a license to use the website and contents for the life of the website.
©️ 2023 WEIN & CO. CREATIVE
FEES & DEPOSITS
A 50% deposit of the total fee is due immediately to begin the website design and development work. The remaining 50% shall become due when the work is completed to your reasonable satisfaction by the online launch date. Wein & Co. reserves the right not to commence any work until the deposit has been paid in full.
The deposit is not refundable if the development work has been started and you terminate the contract through no fault of Wein & Co.
SUPPLY OF MATERIALS
You must supply all materials and information required by Wein & Co. to complete the work in accordance with any agreed specification dates. Such materials may include, but are not limited to, photographs, written copy, logos and other printed material. Where there is any delay in supplying these materials to Wein & Co. which leads to a delay in the completion of work, Wein & Co. has the right to extend any previously agreed deadlines by a reasonable amount.
Where you fail to supply materials, and that prevents the progress of the work, Wein & Co. has the right to invoice you for any part or parts of the work already completed.
VARIATIONS
Wein & Co. is pleased to offer you the opportunity to make revisions to the design. However, Wein & Co. has the right to limit the number of design proposals to a reasonable amount and may charge for additional designs if you make a change to the original design specification.
Once the website theme has been signed off, and Wein & Co. commences the website development phase, only minimal changes can be accepted without additional charges.
Any major deviation from the specification will be charged at the rate of $85.00 per hour.
AGREED SCOPE, PERIOD, PRICE, PROJECT DELAYS & CLIENT LIABILITY
Any projects, services and rates supplied are limited to what is specifically set forth and based on a set number of hours. Any additional services will require an agreed quote on additional hours.
Changes and additions outside the scope of the project will be quoted and invoiced. You will be advised on all costs, changes and additions before commencement of the additional work. Expenses are itemized on each invoice.
Any time frames or estimates that Wein & Co. gives are contingent upon your full co-operation and complete and final content in photography for the work pages. During development there is a certain amount of feedback required in order to progress to subsequent phases. It is required that a single point of contact be appointed from your side and be made available on a daily basis in order to expedite the feedback process.
APPROVAL OF WORK
On completion of the work you will be notified and have the opportunity to review it. You must notify Wein & Co. in writing of any unsatisfactory points within 7 days of such notification. Any of the work which has not been reported in writing to Wein & Co. as unsatisfactory within the 7-day review period will be deemed to have been approved. Once approved, or deemed approved, work cannot subsequently be rejected. The project will be deemed to have been completed and the 50% balance of the project price will become due.
The only exception to the above is if the delays are a result of injury or illness.
REJECTED WORK
If you reject any of Wein & Co.’s work within the 7-day review period, or not approve subsequent work performed by Wein & Co. to remedy any points recorded as being unsatisfactory, and Wein & Co., acting reasonably, consider that you have been unreasonable in any rejection of the work, Wein & Co. can elect to treat this project as at an end and take measures to recover payment for the completed work.
ACCEPTANCE OF WEBSITE
Once the project has been completed, as determined by Wein & Co. Creative, we will notify you either in writing, and provide you with an opportunity to access the website. If you determine that the website does not comply with the project components outlined in the initial meeting, Wein & Co. Creative agrees to;
a) Perform the corrections of errors free of charge to the system Wein & Co. Creative has developed.Wein & Co. Creative is not responsible for errors on third party software.
b) Wein & Co. Creative will carry out simple aesthetic changes, modifications to meet the client’s demands. These changes do not include development of new function into the website.
Any significant changes will require additional funding to complete the requirements.
PAYMENT
Upon completion of the 7-day review period, Wein & Co. will invoice you for the 50% balance of the project. If there are any outstanding payments, Wein & Co. Creative reserves the right to refrain from proceeding with more work for the client.
WARRANTY BY YOU AS TO OWNERSHIP OF INTELLECTUAL PROPERTY RIGHTS
You must obtain all necessary permissions and authorities in respect of the use of all copy, graphic images, registered company logos, names and trade marks, or any other material that you supply to Wein & Co. to include in your website or web applications.
You must indemnify Wein & Co. and hold Wein & Co. harmless from any claims or legal actions related to the content of your website.
SEARCH ENGINES
Wein & Co. does not guarantee any specific position in search engine results for your website. Wein & Co. performs basic search engine optimization according to current best practice.
CONSEQUENTIAL LOSS
Wein & Co. shall not be liable for any loss or damage which you may suffer which is in any way attributable to any delay in performance or completion of the project, however that delay arises.
DISCLAIMER
To the full extent permitted by law, all terms, conditions, warranties, undertakings, inducements or representations whether express, implied, statutory or otherwise (other than the express provisions of these terms and conditions) relating in any way to the services Wein & Co. provides to you are excluded. Without limiting the above, to the extent permitted by law, any liability of Wein & Co. Creative under any term, condition, warranty or representation that by law cannot be excluded is, where permitted by law, limited at our option to the replacement, re-repair or re-supply of the services or the payment of the cost of the services that Wein & Co. was hired to perform.
SUBCONTRACTING
Wein & Co. reserves the right to subcontract any services that Wein & Co. has agreed to perform for you as Wein & Co. sees fit. Wein & Co. will not share any confidential data or logins with subcontractors aside from the website login.
NON-DISCLOSURE
Wein & Co. (and any subcontractors engaged) agree that Wein & Co. will not at any time disclose any of your confidential information to any third party.
ADDITIONAL EXPENSES
You agree to reimburse Wein & Co. for any requested expenses that will be noted in the quote including but not limited to the purchase of templates, third party software, stock photographs, fonts, domain name registration, web hosting or comparable expenses.
BACKUPS
You are responsible for maintaining your own backups with respect to your website and Wein & Co. will not be liable for restoring any client data or client websites except to the extent that such data loss arises out of a negligent act or omission by Wein & Co.
OWNERSHIP OF DOMAIN NAMES & WEB HOSTING
Wein & Co. will recommended an Internet domain registrar and web hosting company where you can purchase a domain name, hosting, web security, and any other items your business may require. Once you create an account, Wein & Co. will require the login credentials in order to set up your website.
GOVERNING LAW
The agreement constituted by these terms and conditions and any proposal will be construed according to and is governed by the laws of Vancouver. You and Wein & Co. Creative submit to the non-exclusive jurisdiction of the courts in and of Vancouver in relation to any dispute arising under these terms and conditions or in relation to any services Wein & Co. performs for you.
CROSS BROWSER COMPATIBILITY
By using current versions of well supported content management systems such as “Wordpress”, Wein & Co. endeavours to ensure that the web sites Wein & Co. creates are compatible with all current modern web browsers such as the most recent versions of Internet Explorer, Firefox, Google Chrome and Safari. Third party extensions, where used, may not have the same level of support for all browsers. Where appropriate Wein & Co. will substitute alternative extensions or implement other solutions, on a best effort basis, where any incompatibilities are found.
E-COMMERCE
You are responsible for complying with all relevant laws relating to e-commerce, and to the full extent permitted by law will hold harmless, protect, and defend and indemnify Wein & Co. Creative and its subcontractors from any claim, penalty, tax, tariff loss or damage arising from your or your clients’ use of Internet electronic commerce.
AUTHORIZATION
You authorize Wein & Co. Creative to perform services which may include, but is not limited to, accessing your domain control panels, email hosting, DNS, hosting account and disk space, creating databases and applications, and submitting the project to search engines.
OWNERSHIP
You have ownership of the website supplied by Wein & Co. Creative once it is fully paid.Wein & Co. Creative will at all times be and remain the sole and exclusive owner of any custom web development or software created in any format used or made part of the website which is not provided by you or a third party (open source). 3rd Party software such as plugins remain the property of Wein & Co. Creative, and may not be transferred without approval from Wein & Co. Creative. Except as expressly authorized by Wein & Co. Creative, you will not copy, modify, distribute or transfer (by any means), display, sublicense, rent, reverse engineer, decompile or disassemble Wein & Co. Creative’s properties.
LICENSING
Once you have paid Wein & Co. in full for our work we grant to you a license to use the website and contents for the life of the website.
©️ 2023 WEIN & CO. CREATIVE